Terms & Conditions – Concrete Contractors Riverside, CA

Effective Date: [Insert Date]

Welcome to Concrete Contractors Riverside, CA (“we,” “our,” or “us”). By using our website and services, you agree to comply with the following Terms & Conditions. Please read them carefully.

Services

We provide professional concrete services, including but not limited to: driveways, patios, stamped concrete, sidewalks, pool decks, foundations, and related work. Service availability may vary by project type and location.

Estimates & Quotes

  • All quotes provided are based on the information you supply and are valid for a limited time.
  • Final costs may vary depending on site conditions, materials, and customer-approved changes.
  • We reserve the right to modify or withdraw an estimate if additional work or changes are required.

Payments

  • A deposit may be required before work begins.
  • Full payment must be made upon project completion unless otherwise agreed in writing.
  • Accepted payment methods include [insert payment methods, e.g., cash, check, credit card].
  • Late payments may be subject to fees or interest charges.

Scheduling & Project Completion

  • We will provide an estimated start and completion date. However, timelines may change due to weather, material availability, or unforeseen circumstances.
  • Delays caused by conditions outside our control will not make us liable for damages.

Customer Responsibilities

  • Ensure access to the worksite.
  • Obtain necessary permits (unless otherwise agreed that we will handle them).
  • Keep children, pets, and personal items away from work areas.

Warranties & Limitations

  • We strive to deliver high-quality workmanship. Specific warranties will be provided in writing for certain services.
  • Natural variations in concrete color, texture, and minor cracking are common and not considered defects.
  • We are not liable for damages caused by misuse, lack of maintenance, or third-party work after project completion.

Liability

  • We carry [insert liability insurance details if available].
  • We are not responsible for indirect, incidental, or consequential damages.
  • Our liability is limited to the value of the services provided

Cancellations & Refunds

  • Customers may cancel prior to project commencement, subject to deposit and preparation costs.
  • Once work has started, refunds will be limited to unperformed services and unused materials.

Website Use

  • The content on our website is for informational purposes only.
  • You may not copy, distribute, or misuse any materials without permission.

Governing Law

These Terms & Conditions are governed by the laws of the State of California. Any disputes will be resolved in the courts of Riverside County, CA.